History of Film Genres Essay Example | Topics and Well Written Essays - 1250 words

History of Film Genres - Essay Example Although that is the truth of the situation in the entertainment industry, the reality of the film-making world is that all of these films are actually categorized per genre. These genres include but are not limited to historical subject, intended impacts, formal criteria, subject matter, and finally, film style. Films generally classify their type of film per genre. By doing so, the movie aficionados and film buffs are given a chance to fully grasp and understand the evolution of our society via films. The slow but sure evolution of film, from the silent films to the colored talkies, to the high tech 3-D films that we have in the cinemas today all focus on the changes and development of culture or historical period within which certain films are produced (â€Å"The History and Evolution of Genres†). It is through this developmental context that Hollywood managed to produce such a diverse set of films stemming from the Western hero in the 1940's and 50's which eventually evolv ed into group heroism as explored in the 1960's and 70's. This group heroism exposed the shift in our society from the open land, pioneering work place of man towards the more organized group of working people in corporations and companies. Eventually, the increase of interest from within our society in the urban crime and international espionage era of the 1970's and 1980's gave way to the current trend of police/detective and spy / thriller genres (â€Å"The History and Evolution of Genres†). As seen in the above listing of film genres, one can note that films are composed of various forms which are identifiable by type. This means that the film categories or classifications can be done based upon a specific criteria. These criteria could be based upon films that have recurring/similar/familiar/instantly recognizable patterns, syntax, film techniques/conventions. content and subject matter, themes, mood, period, plot, central narrative events, motifs, styles, structures, si tuations, recurring icons based upon influence on society, stock characters, or even film stars. Some of these films could even by hybrid type and therefore employ the use of several genres in one film, this is what is known as a hybrid film in Hollywood (Dirks, Tim â€Å"Main Film Genres†). Historically, one of the most popular film genres includes are epic films such as The Ten Commandments, Quo Vadis, and Gone with the Wind. These types of films cater mostly to audiences that have a keen interest in costume dramas, historical dramas, war films, medieval romps, or period pictures. Although epic films have been known to share the elements of an adventure film due to their shared need for a vast, panoramic backdrop, epics still tend to stand under its own spotlight due to the uniqueness of the production values. These production values include but are not limited to: ... an historical or imagined event, mythic, legendary, or heroic figure, and add an extravagant setting and l avish costumes, accompanied by grandeur and spectacle, dramatic scope, high production values, and a sweeping musical score (Dirks, Tim â€Å"Main Film Genres†). Although the epic and war films share certain contexts when it comes to the story being told due to the lavish budgets, costumes, and settings, these two particular genres tell two different stories. While the epic can tell the story of an imagined event or heroic war figure, the war film depicts the cold-hearted brutality and heart breaking real life events

Law of Contract Case Study Example | Topics and Well Written Essays - 750 words

Law of Contract - Case Study Example The requirement for the program is usually postpones or suspended for a limited period of time, and may require notice in order to rely on the contractual clause."1 Whether the bad weather can classified as force majeure making the delay acceptable is dependent upon the force majeure clause in the building contract that the parties entered into. Said clause should contain: According to the case of Paradine v Jane3, it is necessary to adhere to the strict and literal application of contractual terms. In that case the defendant refused to pay rent since he was no longer in possession of the land. The defendant was made to pay rent since the court ruled that there was no express or implied terms within their contract to grant a reprieve in such circumstances. In the event that the agreement between the parties does not clearly state or cover the issues at hand, the basic agreement contained in UK law regarding Force Majeure is found in the Standard Building Contract or SBC Item 13. The SBC states that a contractor is entitled to an extension of time in cases of "other relevant events such as exceptionally adverse weather conditions, specified perils, civil commotion or terrorism, strike and the execution by the UK government of any statutory power which directly affects the execution of the works after the base date."4 The performance of the obligation is deemed suspended until the passing of the force majeure and thus it will create the effect of extending the time allotted to finish obligation as discussed in the case of Tenneco Canada Inc. V British Columbia Hydro and Power Authority.5 Accordingly if the workers strike, a circumstance considered by the court as a force majeure, caused the direct cessation of the Tenneco's electric supply then Tenneco would be granted a reprieve from payment of the monthly demand charge on top of the electricity bill. But since the stoppage of work caused by the strike did not prevent Tenneco from using the electricity hence he must pay the consequent monthly demand charge. The obligation to pay was not deemed suspended. In the case of Snograss the inclement weather condition caused work stoppages and delays, hence the period to complete the obligation must be suspended pending the passage of the force majeure. This being the rule of law, Snodgrass contention is valid. The reason of force majeure causing the delay is valid. The additional time of 10 days it took Snodgrass to finish the first fifty bungalows is valid and reasonable. Hence the breach of contract is excused and the Newchestham Borough Council cannot terminate the same nor is it entitled to